Billion Dollar Boondoggle Act of 2025

Summary

Billion Dollar Boondoggle ActThis act requires the Office of Management and Budget (OMB) to collect information from federal agencies and report to Congress regarding projects that are behind schedule or have expenditures that have exceeded the original cost estimate. Specifically, the act requires OMB to issue guidance directing federal agencies to annually submit specified information to OMB regarding certain federally funded projects that (1) are more than five years behind schedule, or (2) have expenditures that are at least $1 billion more than the original cost estimate for the project. Among other information, the agencies must submit to OMBa description of each project;an explanation of any change to the original scope of the project;the original and current expected dates for the completion of the project;the original and current cost estimates adjusted for inflation; an explanation for any delays in completing the project or increases in the cost; andthe amount of and rationale for any award, incentive fee, or other type of bonus awarded for the project.The act also requires OMB to submit an annual report to Congress containing the information submitted by the agencies and post the report on the OMB website.

Sources & documents

• Official source
• Full text
• House weekly schedule
• House FloorCast
• Congressional Record
• Hearings to examine sunshine week, focusing on bringing secret government spending to light, including S.766, to require an annual report of taxpayer-funded projects that are over budget and behind schedule, S.872, to amend the Federal Funding Accountability and Transparency Act of 2006 to ensure that other transaction agreements are reported to USAspending.gov, S.4059, to provide requirements for Executive agency spending at the end of a fiscal year, S.4130, to pub a public price tag on all projects supported with taxpayer dollars, and S.1199, to extend the statute of limitations for fraud under certain pandemic programs.
• Hearings to examine sunshine week, focusing on bringing secret government spending to light, including S.766, to require an annual report of taxpayer-funded projects that are over budget and behind schedule, S.872, to amend the Federal Funding Accountability and Transparency Act of 2006 to ensure that other transaction agreements are reported to USAspending.gov, S.4059, to provide requirements for Executive agency spending at the end of a fiscal year, S.4130, to pub a public price tag on all projects supported with taxpayer dollars, and S.1199, to extend the statute of limitations for fraud under certain pandemic programs.
• Business meeting to consider S.854, to amend title 31, United States Code, to establish the Life Sciences Research Security Board, S.855, to require executive branch employees to report certain royalties, S.269, to improve coordination between Federal and State agencies and the Do Not Pay working system, S.81, to require a guidance clarity statement on certain agency guidance, S.861, to streamline the sharing of information among Federal disaster assistance agencies, to expedite the delivery of life-saving assistance to disaster survivors, to speed the recovery of communities from disasters, to protect the security and privacy of information provided by disaster survivors, S.766, to require an annual report of taxpayer-funded projects that are over budget and behind schedule, S.872, to amend the Federal Funding Accountability and Transparency Act of 2006 to ensure that other transaction agreements are reported to USAspending.gov, S.727, to correct the inequitable denial of enhanced retirement and annuity benefits to certain U.S. Customs and Border Protection Officers, S.874, to ensure that whistleblowers, including contractors, are protected from retaliation when a Federal employee orders a reprisal, S.594, to amend the Post-Katrina Management Reform Act of 2006 to repeal certain obsolete requirements, S.865, to amend the Lobbying Disclosure Act of 1995 to require certain disclosures by registrants regarding exemptions under the Foreign Agents Registration Act of 1938, as amended, S.856, to amend the Lobbying Disclosure Act of 1995 to clarify a provision relating to certain contents of registrations under that Act, S.850, to amend the Northern Border Security Review Act to require updates to the northern border threat analysis and the northern border strategy, S.848, to provide for joint reports by relevant Federal agencies to Congress regarding incidents of terrorism, and S.572, to enhance the effectiveness of the Shadow Wolves Program; to be immediately followed by a business meeting to consider S.1498, to amend chapter 131 of title 5, United States Code, to prohibit transactions involving certain financial instruments by Members of Congress, the nominations of Pedro Allende, of Florida, to be Under Secretary for Science and Technology, and Sean Plankey, of Pennsylvania, to be Director of the Cybersecurity and Infrastructure Security Agency, both of the Department of Homeland Security, Christopher Fox, of Virginia, to be Inspector General of the Intelligence Community, Office of the Director of National Intelligence, and Edward Aloysius O'Connell, of the District of Columbia, to be an Associate Judge of the Superior Court of the District of Columbia for the term of fifteen years.